Loading...
HomeMy WebLinkAboutCO 2025-221 - EMCOR SERVICES – MESA ENERGY SYSTEMS, INC.CITY OF RANCHO CUCAMONGA PUBLIC WORKS SERVICES DEPARTMENT CONTRACT EMCOR SERVICES – MESA ENERGY SYSTEMS, INC. FOR VICTORIA GARDENS DOMESTIC WATER HEATER REPLACEMENT (PW 2025-158) AWARD DATE: October 30, 2025 City of Rancho Cucamonga CONTRACT NUMBER 2025-221 Docusign Envelope ID: 0EDADE46-D806-45A5-A420-AE2538AAF6F6 PW Bid Form Open Market Projects rev November 16, 2023 October 29, 2025 Emcor Services – Mesa Energy Systems, Inc. (“Contractor” or “bidder”) Attn: Allie M. Ross 2 Cromwell Irvine, CA. 92618 SUBJECT: REQUEST FOR OPEN MARKET PUBLIC WORKS BID Victoria Gardens Domestic Water Heater Replacement ($75,000 or less) Project No. PW 2025-158 Dear Emcor: The City of Rancho Cucamonga invites your proposal for providing Victoria Gardens Domestic Water Heater Replacement within the City of Rancho Cucamonga. This is a request for an informal bid made pursuant to Public Contract Code Section 22032(a) and R.C.M.C Section 3.08.110.B.1. Your proposal must actually be received in the City’s Department of Public Works, attention: Jeff Geith, 8794 Lion Street, Rancho Cucamonga, CA, 91730, on or before 2:00 p.m. on November 10, 2025. The City’s time stamp shall be conclusive as to the date and time of receipt. Contractor assumes all risk of untimely or lack of receipt for bids not personally and timely delivered as required above. Late bids will not be opened and will be returned. GENERAL SCOPE OF WORK: Contractor/bidder shall furnish all necessary labor, tools, materials, appliances, and equipment to complete the Project as described in the Scope of Work and Service requirements (“Work” or “Services”), including, but not necessarily limited to: 1.Coordination and management of the Services required, including review of the Project site, improvement plans, specifications and special provisions, if any. 2.Inspection of the Work on the Project before, during and/or after construction to ensure conformance with Federal, State and City statutes, regulations, ordinances, guidelines, applicable standards, specifications, plans, laws and accepted standard construction practices. 3.The keeping of proper records and reports, photographs and videos, including but not limited to, certifications of compliance, submittals, shop drawings, materials reports, and other related documents received. Contractor shall deliver documents to the City when generated, prepared or received. 4.Designation of a person or persons fully qualified to perform the Services. 5.Attend any meetings that the City deems necessary. 6.Installation of removal of existing domestic boiler including installation of new Raypak Model WH1-HD401. 7.Performance of the Work in compliance with the Standard Plans for Public Works Construction, Latest Edition with Supplements published by the American Public Works Association; the City of Rancho Cucamonga Standard Drawings, Latest Edition, and the attached specifications, all of which are hereby incorporated into this Request for Bid along with the agreement (if any) that is awarded as a result of this Request. Docusign Envelope ID: 0EDADE46-D806-45A5-A420-AE2538AAF6F6 PW Bid Form Open Market Projects rev November 16, 2023 Any Scope of Services, Contingencies, Special Instructions and/or Terms and Conditions applicable to this Proposal and any Purchase Order created thereafter, are also incorporated by reference herein, and shall be effective as of the issue date of Purchase Order (the “Effective Date”), and shall remain in full force and effect until one hundred eighty days after (i) the filing of a notice of completion; or (ii) City has accepted the Work in writing and has made final payment if a notice of completion is not required to be filed; unless sooner terminated by the City. LABOR CODE COMPLIANCE The Work and Services constitute a public work requiring payment of prevailing wages and compliance with other provisions of the California Labor Code, as set forth in the attached document entitled “California Labor Code Compliance.” LICENSES: At the time of submitting a bid (or contract award if the Project is federally funded), and at all times during the term of the Agreement if awarded, Contractor shall possess a current, valid Class C-4, Boiler, Hot Water Heating and Steam Fitting, License in accordance with the provisions of the Contractor's License Law (California Business and Professions Code, Section 7000, et seq.) and rules and regulations adopted pursuant thereto. Pursuant to Section 7028.15 of the California Business and Professions Code, the Contractor ’s State contractor’s license number shall be set forth on the bid, together with the expiration date, and the bid shall be signed by the Contractor declaring, under penalty of perjury, that the information being provided is true and correct. SUBCONTRACTORS: In the bid, the Contractor shall list the name, business address, the California contractor license number, and public works contractor registration number issued pursuant to Section 1725.5 of the Labor Code, of each subcontractor who will perform work or labor or render service to the bidder in or about the construction of the Work or improvement, or a subcontractor licensed by the State of California who, under subcontract to the Contractor, specially fabricates and installs a portion of the work or improvement according to detailed drawings contained in the plans and specifications, in an amount in excess of one-half of 1 percent of the Contractor’s total bid or, in the case of bids or offers for the construction of streets or highways, including bridges, in excess of one-half of 1 percent of the Contractor’s total bid or ten thousand dollars ($10,000), whichever is greater. The Contractor shall be prohibited from performing work on this Project with a subcontractor who is ineligible to perform work on the Project pursuant to Section 1777.1 or 1777.7 of the Labor Code. INSURANCE: If awarded, the Contractor shall not commence work under the contract until the Contractor has obtained all insurance described and set forth in the attached form of Agreement. BONDS: If the contract amount exceeds $25,000, California Civil Code Section 9550 requires the Contractor to provide a payment bond in 100% of the contract amount. If the contract amount is $25,000 or less, the City does not require the foregoing payment bond. If the contract amount exceeds $25,000, a performance bond in 100% of the contract amount is required. If the contract amount is $25,000 or less, the City does not require the foregoing performance bond. AWARD OF CONTRACT: The City will evaluate bids received utilizing any lawful method of scoring. Price may or may not be the primary selection factor. If awarded, an agreement will be awarded based on the bid determined to be the most beneficial to the City. The City shall be the sole judge in the ranking process utilized in making such determination. The City reserves the right, in its sole discretion, to reject any or all bids, to withdraw this Request for Public Work Bid at any time prior to any award, and to waive any irregularity in any bid. The City shall not be liable for any costs incurred in preparing and submitting any bid. If a contract is awarded, then, as a condition of the award, the Contractor shall execute the attached form of agreement (“Agreement”) and provide insurance coverage in the form and limits set forth in the Agreement. Docusign Envelope ID: 0EDADE46-D806-45A5-A420-AE2538AAF6F6 PW Bid Form Open Market Projects rev November 16, 2023 CITY BUSINESS LICENSE: The Contractor must have a City Business License as a condition of being awarded a City contract. COMMENCEMENT OF WORK: Unless otherwise specified in writing, no materials may be ordered, or work completed prior to the issuance of a written Notice to Proceed by the City. LIQUIDATED DAMAGES: Liquidated damages are applicable to this procurement. The Contractor agrees to enter into the Agreement within the earlier of fifteen (15) days from the date the City gives public notice of award of the contract or upon written notice to the Contractor by City after the fifteen (15) days. Thereafter, Contractor shall complete the work within Fifteen working days from the date specified in the City’s written Notice to Proceed served on the Contractor. The Contractor agrees to the assessment of liquidated damages in the amount of one hundred dollars ($100) for each calendar day the work remains incomplete beyond the completion date. City may deduct the amount of any assessed liquidated damages, from any monies due or that may become due the Contractor under the contract. Progress payments made after the scheduled date of completion shall not constitute a waiver of liquidated damages. CONTRACTOR'S LIABILITY: Contractor shall indemnify, defend and hold the City of Rancho Cucamonga and its elected officials, officers, agents and employees free and harmless in accordance with the indemnity set forth in the Agreement. NON-DISCRIMINATION: No discrimination shall be made in the employment of persons upon public works because of age, disability, race, color, religion, sex, sexual orientation or national origin of such persons, and every contractor for public works violating this section is subject to all the penalties imposed for a violation of Division 2, Part 7, Chapter 1 of the Labor Code in accordance with the provisions of Section 1735 of said Code. CONTRACT PRICE AND PAYMENT: City shall pay to the Contractor for furnishing the material and doing the prescribed Work per the NOT-TO-EXCEED unit prices and/or lump sum, as applicable, set forth in Contractor's bid. SUBMISSION: Contractor may submit bids in a sealed envelope or via email attachment provided bids are appropriately signed. The envelope shall be marked, or email subject shall be titled “Bid - City of Rancho Cucamonga” and the name of the Project. The Contractor shall also include a description of the Contractor’s qualifications relevant to the required Work. Experience working with local public agencies is a must. Having an office within a 30-mile radius of the City is preferred. Contractor shall also include a signed acknowledgement of receipt of any addendum(s) to the Request for Public Works Bid issued prior to the bid submission deadline. The City shall not be liable for any costs incurred in preparing and submitting any bid, whether or not a contract is awarded. Furthermore, the City reserves the right to reject any or all bids without liability for any costs. Any bid may be withdrawn prior to the date and time set for receipt of bids. Unless timely withdrawn, all bids will become the property of the City and will be subject to public review pursuant to the California Public Records Act, regardless of any marking thereon, such as “confidential”, “trade secret”, etc. If you have any questions, please contact the undersigned at 1-909-774-4159 or email at Jeff.Geith@CityofRC.us. Sincerely, PUBLIC WORKS SERVICES Jeff Geith Facility Supervisor Attachments: Docusign Envelope ID: 0EDADE46-D806-45A5-A420-AE2538AAF6F6 PW Bid Form Open Market Projects rev November 16, 2023 (1)Bid Proposal Form (2)Contract Agreement (3) Specifications (4)California Labor Code Compliance (5)Non-Collusion Declaration Docusign Envelope ID: 0EDADE46-D806-45A5-A420-AE2538AAF6F6 Bidder Name & CSLB No. P-1 BID PROPOSAL FORM FOR “Victoria Gardens Domestic Water Heater Replacement” TO THE CITY OF RANCHO CUCAMONGA: The undersigned bidder declares that he has carefully examined the location of the proposed work, that he has examined the Plans, Special Provisions and Specifications, and read the accompanying information, and hereby proposes and agrees, if this proposal is accepted, to furnish all material and equipment to do all the work required to complete the said work in accordance with the Plans, Special Provisions and Specifications, in the time and manner therein prescribed for the unit cost and lump sum amounts set forth in the schedule on the following Proposal. Item No. Description Qty. Unit Unit Price Price 1.Provide and install one (1) new Raypak Model WH1- HD401 water heater to replace existing.1.LS TOTAL AMOUNT IN NUMBERS: _______________________________________________________________ TOTAL AMOUNT IN WORDS:__________________________________________________________________ $21,450.00 $21,450.00 $21,450.00 twenty one thousand four hundred fifty dollars Mesa Energy Systems, Inc., 611215 Docusign Envelope ID: 0EDADE46-D806-45A5-A420-AE2538AAF6F6 Bidder Name & CSLB No. P-2 Bidder Information for Victoria Gardens Domestic Water Heater Replacement Company Name: Company Address: CSLB No: DIR No: Telephone No: Email Address: Web Address: Authorized Representative (Print): Title: Signature: Date: Vendor routing for contract signatures via DocuSign Name Title Email Mesa Energy Systems, Inc.2 Cromwell Irvine, CA 92618 61125 kgrace@emcor.net Kristi Grace 949-460-8800 mesaenergy.com VP of Service Operations 10/30/2025 Kristi Grace VP of Service Operations kgrace@emcor.net Mesa Energy Systems, Inc., 611215 Docusign Envelope ID: 0EDADE46-D806-45A5-A420-AE2538AAF6F6 Bidder Name & CSLB No. C-1 AGREEMENT This Agreement (“Agreement”) is made and entered into as of the date executed by the City Clerk and the City Manager, by and between Emcor Services – Mesa Energy Systems, Inc., a HVAC Contractor hereinafter referred to as the "Contractor", and the City of Rancho Cucamonga, California, hereinafter referred to as "City." WHEREAS, pursuant to the Request for Open Market Public Works Bid, bids were received on or before the date specified in said notice; and WHEREAS, City did accept the bid of Contractor; and WHEREAS, City has authorized the City Manager, or designee, to enter into certain written contracts for furnishing labor, equipment, and material for the construction of Public Works. NOW THEREFORE, in consideration of the mutual covenants herein contained, it is agreed: 1.GENERAL SCOPE OF WORK: Contractor shall furnish all necessary labor, tools, materials, appliances, and equipment for and do the work necessary to satisfactorily complete the “Victoria Gardens Domestic Water Heater Replacement” project. The foregoing work (“Work”) shall be performed in accordance with the provisions of this Agreement, specifications and standards referenced in Section 2 of this Agreement and those on file in the office of the City Engineer, and in accordance with bid prices hereinafter mentioned and with the instructions of the City Engineer. The Work shall be performed in compliance with any and all applicable local, State, and federal laws, statutes, and regulations. 2.CONTRACT DOCUMENTS: The documents, specifications, and standards referenced in Section 1, above, the Request for Open Market Public Works Bid dated 10/29/2025 and any addendums thereto, the Standard Specifications for Public Works Construction, Latest Edition, with Supplements published by the American Public Works Association the Standard Plans for Public Works Construction, Latest Edition, with Supplements published by the American Public Works Association; the City of Rancho Cucamonga Standard Drawings, Latest Edition, and any and all other provisions, instructions, specifications, and plans referenced therein and/or attached hereto, and the Contractor’s bid, all of which are incorporated by reference herein, together with this Agreement, shall constitute the entire agreement between the parties. This Agreement is intended to require a complete and finished piece of work and anything necessary to complete the work properly and in accordance with the law and lawful governmental regulations shall be performed by the Contractor whether set out specifically in the contract or not. Should it be ascertained that any inconsistency exists between the individual documents described and this written agreement, the provisions of this Agreement, then the Request for Open Market Public Works Bid, shall control. 3.LIQUIDATED DAMAGES: Liquidated damages apply to this Agreement. The Contractor agrees to the assessment of liquidated damages in the amount of one hundred dollars ($100) for each calendar day the Work remains incomplete beyond the expiration of the completion date. City may deduct the amount thereof from any monies due or that may become due the Contractor under this Agreement. Progress payments made after the scheduled date of completion shall not constitute a waiver of liquidated damages. 4.INSURANCE: The Contractor shall not commence work under this Agreement until Contractor has obtained all insurance required hereunder in a company or companies acceptable to City nor shall Mesa Energy Systems, Inc., 611215 Docusign Envelope ID: 0EDADE46-D806-45A5-A420-AE2538AAF6F6 Bidder Name & CSLB No. C-2 the Contractor allow any subcontractor to commence work on a subcontract until all insurance required of the subcontractor has been obtained. The Contractor shall take out and maintain at all time during the life of this contract the following policies of insurance: a.Workers Compensation Insurance: Before beginning work, the Contractor shall furnish to the Engineer a certificate of insurance as proof that it has taken out full compensation insurance for all persons whom it may employ directly or through subcontractors in carrying out the Work specified herein, in accordance with the laws of the State of California. Such insurance shall be maintained in full force and effect during the period covered by this Agreement. The policy shall be endorsed to waive the right of subrogation. In accordance with the provisions of Section 3700 of the California Labor Code, every contractor shall secure the payment of compensation to his employees. Contractor, prior to commencing work, shall sign and file with the City a certification as follows: "I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for worker's compensation or to undertake self-insurance in accordance with the provisions of that Code, and I will comply with such provisions before commencing the performance of the work of this contract." b.For all operations of the Contractor and/or any subcontractor in performing the Work provided for herein, insurance with the following minimum limits and coverage: (1)Commercial General Liability - Bodily Injury (not auto) $2,000,000 each person; $2,000,000 each accident. (2)Commercial General Liability - Property Damage (not auto) $1,000,000 each accident; $2,000,000 aggregate. (4)Automobile (any auto) - Bodily Injury $2,000,000 each person; $3,000,000 each accident. (5)Automobile (any auto) - Property Damage $2,000,000 each accident. c.Each such policy of insurance provided for in paragraph "b." shall: (1)Be issued by an insurance company approved in writing by City, which is qualified to do business in the State of California. The insurance company shall have an A.M. Best Company Rating Guide rating of not less than A:VII; (2)Name as additional insureds the City, its elected officials, officers, volunteers, agents and employees, and any other parties specified in the bid documents to be so included; (3)Specify it acts as primary insurance and that no insurance held or owned by the designated additional insured shall be called upon to cover a loss under said policy; (4)Contain a clause substantially in the following words: "It is hereby understood and agreed that this policy may not be canceled, nor the amount of the coverage thereof reduced until thirty (30) days after receipt by City of a written notice of such cancellation or reduction of coverage as evidenced by receipt of a registered letter." Mesa Energy Systems, Inc., 611215 Docusign Envelope ID: 0EDADE46-D806-45A5-A420-AE2538AAF6F6 Bidder Name & CSLB No. C-3 (5)Otherwise, be in form satisfactory to City. (6)Waives all right of subrogation against the additional insureds in the policy of insurance provided for in paragraph "b." by reason of any claim arising out of or connected with the operations of Contractor or any subcontractor in performing the Work provided for herein; (7)Provides it shall not be canceled or altered without thirty (30) days' written notice thereof given to City by registered mail. e.The Contractor shall at the time of the execution of this Agreement present the original policies of insurance required in paragraphs "a." and "b." hereof, or present a certificate and original endorsements of the insurance company, showing the issuance of such insurance, and the additional insureds and other provisions required herein. 5.LABOR CODE COMPLIANCE: At all times herein, the Contractor shall comply with all applicable provisions of the California Labor Code including those set forth in the attachment hereto marked “CALIFORNIA LABOR CODE COMPLIANCE.” 6.CONTRACTOR'S LIABILITY: The City of Rancho Cucamonga and its elected officials, officers, agents and employees shall not be answerable or accountable in any manner for any loss or damage that may happen to the work or any part thereof, or for any of the materials or other things used or employed in performing the work; or for injury or damage to any person or persons, either workers, employees of the Contractor, his subcontractors, or the public, or for damage to adjoining or other property, from any cause whatsoever arising out of or in connection with the performance of the Work. The Contractor shall be responsible for any damage or injury to any person or property resulting from defects or obstructions or from any cause whatsoever, except the sole negligence or willful misconduct of the City, its employees, servants, or independent contractors who are directly responsible to City during the progress of the Work or at any time before its completion and final acceptance. To the maximum extent permitted by law, the Contractor will indemnify, defend, and hold the City, its elected officials, officers, employees, volunteers, and agents serving as independent contractors in the role of City officials (“Indemnitees”), free and harmless with respect to any and all actions, claims, damages to persons or property, stop notices, penalties, obligations, and/or liabilities that may be asserted or claimed by any person, firm, entity, corporation, political subdivision, or other organization, arising out of or incurred in connection with the Work, Services, operations, acts, omissions, or activities of the Contractor, its owners, agents, employees, subcontractors, and/or invitees, whether or not there is concurrent passive or active negligence on the part of any of the Indemnitees, but excluding such actions, claims, damages to persons or property, penalties, obligations, or liabilities arising from the sole negligence or willful misconduct of any of the Indemnitees, and in connection therewith: a.The Contractor will defend any action or actions filed in connection with any of said claims, damages, penalties, obligations, or liabilities and will pay all costs and expenses, including attorneys' fees incurred in connection therewith. b.The Contractor will promptly pay any judgment or award rendered against the Contractor or any of the Indemnitees covering such claims, damages, penalties, obligations, and liabilities arising out of or in connection with the Work, operations, or activities of the Contractor hereunder or reasonable settlement in lieu of judgment or award, and the Contractor agrees to save and hold the Indemnitees harmless therefrom. Mesa Energy Systems, Inc., 611215 Docusign Envelope ID: 0EDADE46-D806-45A5-A420-AE2538AAF6F6 Bidder Name & CSLB No. C-4 c. In the event any of the Indemnitees is made a party to any action or proceeding filed or prosecuted against the Contractor for damages or other claims arising out of or in connection with the project, operation, or activities of the Contractor hereunder, the Contractor agrees to pay to City any and all costs and expenses incurred by City or any of the Indemnitees in such action or proceeding together with reasonable attorneys' fees. So much of the money due to the Contractor under and by virtue of this Agreement as shall be considered necessary by City may be retained by City until disposition has been made of such actions or claims for damage as provided above. 7. MANDATORY TERMS: a. The City shall pay Contractor for its services in accordance with the agreed-upon rates as set forth in Section 9, described in the Bid Proposal Form (P-1) and incorporated herein by this reference. Pursuant to Public Contract Code Section 20104.50, the City shall make any progress payment within thirty (30) days after receipt of an undisputed and properly submitted payment request from Contractor. Upon receipt of a payment request, the City shall review the payment request as soon as practicable to determine whether the payment request is proper, and if any payment request is determined not to be suitable for payment, the City shall return the payment request to the Contractor as soon as practicable, but not later than seven (7) days after receipt, with a document setting forth in writing the reasons why the payment request is not proper. b. In the event of any dispute or controversy with the City over any matter whatsoever, the Contractor shall not cause any delay or cessation in or of Work, but shall proceed with the performance of the Work in dispute. The Contractor shall retain any and all rights provided that pertain to the resolution of disputes and protests between the parties. The Disputed Work will be categorized as an “unresolved dispute” and payment, if any, shall be as later determined by agreement or a court of law. The Contractor shall keep accurate, detailed records of all Disputed Work, claims and other disputed matters. All claims arising out of or related to the Contract Documents or this Project, and the consideration and payment of such claims, are subject to the Government Claims Act (Government Code Section 810 et seq.) with regard to filing claims. All such claims are also subject to the dispute procedures set forth in Public Contract Code Section 9204 and Public Contract Code Section 20104, et seq. (Article 1.5), to the extent each is applicable. This Contract hereby incorporates those provisions as though fully set forth herein. Thus, the Contractor or any Subcontractor must file a claim in accordance with the Government Claims Act as a prerequisite to filing a construction claim in compliance with Section 9204 and Section 20104 et seq. (if applicable), and must then adhere to Section 20104, et seq. and Section 9204, as applicable, pursuant to the definition of “claim” as individually defined therein. c. Pursuant and subject to Public Contract Code Section 22300, the substitution of securities for any moneys withheld by the City to ensure performance under a contract is permitted. d. The City or its representative shall have the option of inspecting and/or auditing all records and other written materials used by Contractor in preparing its billings to the City as a condition precedent to any payment to Contractor. Contractor will promptly furnish documents requested by the City. Additionally, pursuant to Government Code Section 8546.7, if this Agreement involves the expenditure of public funds in excess of ten thousand dollars ($10,000), Contractor shall be subject to State Auditor examination and audit at the request of the City or as part of any audit of the City, for a period of three (3) years after final payment under this Agreement. Mesa Energy Systems, Inc., 611215 Docusign Envelope ID: 0EDADE46-D806-45A5-A420-AE2538AAF6F6 Bidder Name & CSLB No. C-5 e.Pursuant to Public Contract Code Section 7103.5, Contractor offers and agrees to assign to the City all rights, title, and interest in and to all causes of action it may have under Section 4 of the Clayton Act (15 U.S.C. Sec. 15) or under the Cartwright Act (Chapter 2 (commencing with Section 16700) of Part 2 of Division 7 of the California Business and Professions Code) arising from purchases of goods, services, or materials pursuant to the Agreement. This assignment shall be made and become effective at the time the City tenders final payment to Contractor without further acknowledgment by the parties. f.Pursuant to Public Contract Code Section 9201, the City has full authority to compromise or otherwise settle any claim relating to this Contract at any time. The City shall timely notify Contractor of the receipt of any third-party claim relating to the Contract. The City shall be entitled to recover its reasonable costs incurred in providing the notification required by Public Contract Code Section 9201(b). 8.NON-DISCRIMINATION: No discrimination shall be made in the employment of persons upon public works because of age, disability, race, color, religion, sex, sexual orientation or national origin of such persons, and every contractor for public works violating this section is subject to all the penalties imposed for a violation of Division 2, Part 7, Chapter 1 of the Labor Code in accordance with the provisions of Section 1735 of said Code. 9.CONTRACT PRICE AND PAYMENT: City shall pay to the Contractor for furnishing the material and satisfactorily performing the Work, the unit and/or lump sum prices, as applicable, set forth in the Contractor's bid. IN WITNESS WHEREOF, the parties hereto have caused these present to be duly executed with all the formalities required by law on the respective dates set forth opposite their signatures. State of California Contractor's License #: Contractor: Address: By: Signature Name &Title Date: By: Signature Name &Title Date: CITY OF RANCHO CUCAMONGA, CALIFORNIA By: Maritza Martinez, Public Works Services Director Date: Mesa Energy Systems, Inc., 611215 Docusign Envelope ID: 0EDADE46-D806-45A5-A420-AE2538AAF6F6 VP of Service Ops EMCOR Services Mesa Energy 611215 Kristi Grace 2 Cromwell Irvine CA 92618 11/6/2025 | 11:28 AM PST Bidder Name & CSLB No. C-6 Contractor's Business Phone Number: ___________________________________________________. Emergency Name and Phone Number at which Contractor can be reached at any time: ____________ __________________________________________________________________________________ Mesa Energy Systems, Inc., 611215 Docusign Envelope ID: 0EDADE46-D806-45A5-A420-AE2538AAF6F6 949-460-8800 Kristi Grace- 949-254-0748 LC-1 SPECIFICATIONS City of Rancho Cucamonga Domestic Hot Water Heater Replacement Project Location: Victoria Gardens Cultural Center 12505 Cultural Center Drive Rancho Cucamonga, CA 91739 Prepared for: City of Rancho Cucamonga – Public Works Department 1. GENERAL REQUIREMENTS 1.1 Scope of Work The Contractor shall furnish all labor, materials, tools, equipment, and supervision necessary to remove and replace the existing domestic hot water heater at the Victoria Gardens Cultural Center. All work shall be performed in accordance with these specifications and applicable codes and standards. 1.2 Location of Work Victoria Gardens Cultural Center Mechanical Room, 12505 Cultural Center Drive, Rancho Cucamonga, CA 91739. 1.3 Work Hours All work shall be performed during normal business hours, unless otherwise approved by the City. Contractor shall coordinate with facility management to minimize disruption to operations. 2. MATERIALS AND EQUIPMENT 2.1 Water Heater Provide and install One (1) Raypak Model WH1-HD401 or City-approved equivalent. The new unit shall match the capacity, performance, and service connections of the existing system. 2.2 Accessories and Components • Isolation valves (as needed for maintenance) • Pressure relief valve (factory-supplied or field-installed) • Dielectric unions on all water connections • Vent connector and combustion air piping (as required) • Electrical disconnect (if not existing) Docusign Envelope ID: 0EDADE46-D806-45A5-A420-AE2538AAF6F6 LC-2 3. EXECUTION 3.1 Preparation and Safety 1.Lockout/Tagout: Secure electrical and mechanical systems for the existing hot water heater and hot water circulating pump. 2.Drain Down: Safely drain the existing domestic hot water system to remove the heater. 3.Site Protection: Protect surrounding finishes, equipment, and piping during removal and installation. 3.2 Removal of Existing Heater •Disconnect all associated electrical, gas, and plumbing services. •Remove the existing water heater and related components using appropriate rigging equipment. •Properly dispose of removed equipment per local and state environmental regulations. 3.3 Installation of New Heater •Rig and place new Raypak WH1-HD401 heater in the existing location. •Reconnect electrical wiring to match existing connections and comply with CEC. •Reconnect all piping, ensuring watertight and code-compliant joints. •Connect venting system to new heater in accordance with manufacturer’s requirements. •Secure unit to the floor or housekeeping pad as required. 3.4 System Start-Up and Testing •Fill and purge air from the system. •Inspect for leaks at all connections. •Energize the heater and circulating pump. •Test the system for proper operation, including temperature control, combustion, and circulation. •Verify that all safety controls function properly. •Provide start-up documentation and manufacturer’s operating manuals to the City. 4.WARRANTY AND CLOSEOUT 4.1 Warranty Provide a minimum one (1) year warranty on all labor and materials. The manufacturer’s standard equipment warranty shall also apply. 4.2 Submittals Submit the following to the City for approval: •Product data and specifications for the Raypak WH1-HD401 •Manufacturer’s installation instructions •Start-up and test results •Warranty documentation 4.3 Cleanup Upon completion, remove all debris, tools, and materials from the site. Leave the work area in clean condition. Docusign Envelope ID: 0EDADE46-D806-45A5-A420-AE2538AAF6F6 LC-3 Docusign Envelope ID: 0EDADE46-D806-45A5-A420-AE2538AAF6F6 LC-4 CALIFORNIA LABOR CODE COMPLIANCE 1.Contractor acknowledges that this contract is subject to the provisions of Division 2, Part 7, Chapter 1 (commencing with Section 1720) of the California Labor Code relating to public works and the awarding public agency (“City”), and agrees to be bound by all the provisions thereof as though set forth in full herein. 2.This is a public work and requires the payment of prevailing wages for the work or craft in which the worker is employed for any public work done under the contract by Contractor or by any subcontractor pursuant to Section 1771 of the Labor Code. Pursuant to the provisions of Section 1773 of the Labor Code of the State of California, the City has obtained the general prevailing rate of per diem wages and the general rate for holiday and overtime work in this locality for each craft, classification, or type of workman needed to execute this contract from the Director of the Department of Industrial Relations. These rates are on file with the City Clerk or may be obtained at http://www.dir.ca.gov/OPRL/DPreWageDetermination.htm. 3.Copies may be obtained at cost at the City Clerk's office. Contractor shall post a copy of such wage rates at the job site and shall pay the adopted prevailing wage rates as a minimum. Contractor shall comply with the provisions of Sections 1775, 1776, 1777.5, 1777.6, and 1813 of the Labor Code. Pursuant to the provisions of 1775 of the Labor Code, Contractor shall forfeit to the City, as a penalty, not more than $200.00 for each calendar day, or portion thereof, for each laborer, worker, or mechanic employed, paid less than the stipulated prevailing rates for any work done under this contract, by him or by any subcontractor under him, in violation of the provisions of this Agreement. 4.In accordance with Labor Code Sections 1725.5 and 1771.1, no contractor or subcontractor shall be qualified to bid on, be listed in a bid proposal, subject to the requirements of Section 4104 of the Public Contract Code, or engage in the performance of any contract for public work, unless currently registered and qualified to perform public work pursuant to Section 1725.5 [with limited exceptions for bid purposes only under Labor Code Section 1771.1(a)]. 5.Contractor agrees to comply with the provisions of California Labor Code Section 1776 which, among other things, require Contractor and each subcontractor to (1) keep accurate payroll records, (2) certify and make such payroll records available for inspection as provided by Section 1776, and (3) inform the City of the location of the records. The Contractor is responsible for compliance with Section 1776 by itself and all of its subcontractors. 6.Contractor agrees to comply with the provisions of California Labor Code Section 1777.5 concerning the employment of apprentices on public works projects, and further agrees that Contractor is responsible for compliance with Section 1777.5 by itself and all of its subcontractors. 7.Contractor agrees to comply with the provisions of California Labor Code Section 1813 concerning penalties for workers who work excess hours. The Contractor shall, as a penalty to the City, forfeit twenty-five dollars ($25) for each worker employed in the execution of the contract by the Contractor or by any subcontractor for each calendar day during which such worker is required or permitted to work more than 8 hours in any one calendar day and 40 hours in any one calendar week in violation of the provisions of Division 2, Part 7, Chapter 1, Article 3 of the California Labor Code. Docusign Envelope ID: 0EDADE46-D806-45A5-A420-AE2538AAF6F6 LC-5 8.California Labor Code Sections 1860 and 3700 provide that every contractor will be required to secure the payment of compensation to its employees. In accordance with the provisions of California Labor Code Section 1861, Contractor hereby certifies as follows: “I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for workers’ compensation or to undertake self-insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract.” Date Signature 10/30/2025 Docusign Envelope ID: 0EDADE46-D806-45A5-A420-AE2538AAF6F6 ND-1 NONCOLLUSION DECLARATION FORM TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID [Public Contract Code Section 7106] The undersigned declares: I am the ______________________ of ____________________, the party making the foregoing Bid. The Bid is not made in the interest of, or on behalf of, any undisclosed person, partnership, company, association, organization, or corporation. The Bid is genuine and not collusive or sham. The Bidder has not directly or indirectly induced or solicited any other Bidder to put in a false or sham Bid. The Bidder has not directly or indirectly colluded, conspired, connived, or agreed with any Bidder or anyone else to put in a sham Bid, or to refrain from bidding. The Bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the Bid price of the Bidder or any other Bidder, or to fix any overhead, profit, or cost element of the Bid price, or of that of any other Bidder. All statements contained in the Bid are true. The Bidder has not, directly or indirectly, submitted his or her Bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, to any corporation, partnership, company, association, organization, Bid depository, or to any member or agent thereof, to effectuate a collusive or sham Bid, and has not paid, and will not pay, any Person or entity for such purpose. Any person executing this declaration on behalf of a Bidder that is a corporation, partnership, joint venture, limited liability company, limited liability partnership, or any other entity, hereby represents that he or she has full power to execute, and does execute, this declaration on behalf of the Bidder. I declare under penalty of perjury under the laws of the State of California that the foregoing is true and correct and that this declaration is executed on ___________ [date], at ___________________________________________ [city], ______________________ [state]. Signature: Printed Name: Date: Signature: Printed Name: Date: VP of Service Operations Mesa Energy Systems, Inc. 10/30/2025 Irvine CA Kristi Grace 10/30/2025 Docusign Envelope ID: 0EDADE46-D806-45A5-A420-AE2538AAF6F6 A-1 Attachment A – Sample Additional Insured Endorsement, Ongoing Operations Docusign Envelope ID: 0EDADE46-D806-45A5-A420-AE2538AAF6F6 A-2 Attachment B – Sample Additional Insured Endorsement, Completed Operations Docusign Envelope ID: 0EDADE46-D806-45A5-A420-AE2538AAF6F6 A-3 Attachment C – Sample Waiver of Subrogation Docusign Envelope ID: 0EDADE46-D806-45A5-A420-AE2538AAF6F6 Certificate Of Completion Envelope Id: 0EDADE46-D806-45A5-A420-AE2538AAF6F6 Status: Completed Subject: Victoria Gardens Domestic Water Heater Replacement Source Envelope: Document Pages: 22 Signatures: 2 Envelope Originator: Certificate Pages: 5 Initials: 0 Marissa Ostos AutoNav: Enabled EnvelopeId Stamping: Enabled Time Zone: (UTC-08:00) Pacific Time (US & Canada) Marissa.Ostos@cityofrc.us IP Address: 199.201.174.250 Record Tracking Status: Original 11/6/2025 10:56:53 AM Holder: Marissa Ostos Marissa.Ostos@cityofrc.us Location: DocuSign Signer Events Signature Timestamp Kristi Grace kgrace@emcor.net VP of Service Ops Security Level: Email, Account Authentication (None)Signature Adoption: Drawn on Device Using IP Address: 38.72.64.130 Sent: 11/6/2025 11:14:24 AM Viewed: 11/6/2025 11:22:48 AM Signed: 11/6/2025 11:24:27 AM Electronic Record and Signature Disclosure: Accepted: 11/6/2025 11:22:48 AM ID: c576a058-fd89-42d2-95e5-bde026099282 Maritza Martinez maritza.martinez@cityofrc.us Director of Public Works Security Level: Email, Account Authentication (None)Signature Adoption: Pre-selected Style Using IP Address: 199.201.174.250 Sent: 11/6/2025 11:14:24 AM Viewed: 11/6/2025 11:27:07 AM Signed: 11/6/2025 11:28:30 AM Electronic Record and Signature Disclosure: Accepted: 11/6/2025 11:27:07 AM ID: d516536f-fe68-4dab-9a6f-b66bc2eca036 In Person Signer Events Signature Timestamp Editor Delivery Events Status Timestamp Agent Delivery Events Status Timestamp Intermediary Delivery Events Status Timestamp Certified Delivery Events Status Timestamp Carbon Copy Events Status Timestamp City Clerk clerkcontracts@cityofrc.us City Clerk City of Rancho Cucamonga Security Level: Email, Account Authentication (None) Sent: 11/6/2025 11:14:25 AM Viewed: 11/25/2025 11:00:00 AM Electronic Record and Signature Disclosure: Not Offered via Docusign Witness Events Signature Timestamp Notary Events Signature Timestamp Envelope Summary Events Status Timestamps Envelope Sent Hashed/Encrypted 11/6/2025 11:14:25 AM Certified Delivered Security Checked 11/6/2025 11:27:07 AM Signing Complete Security Checked 11/6/2025 11:28:30 AM Completed Security Checked 11/6/2025 11:28:30 AM Payment Events Status Timestamps Electronic Record and Signature Disclosure ELECTRONIC RECORD AND SIGNATURE DISCLOSURE From time to time, City of Rancho Cucamonga City Clerk's Office (we, us or Company) may be required by law to provide to you certain written notices or disclosures. Described below are the terms and conditions for providing to you such notices and disclosures electronically through the DocuSign system. Please read the information below carefully and thoroughly, and if you can access this information electronically to your satisfaction and agree to this Electronic Record and Signature Disclosure (ERSD), please confirm your agreement by selecting the check-box next to ‘I agree to use electronic records and signatures’ before clicking ‘CONTINUE’ within the DocuSign system. Getting paper copies At any time, you may request from us a paper copy of any record provided or made available electronically to you by us. You will have the ability to download and print documents we send to you through the DocuSign system during and immediately after the signing session and, if you elect to create a DocuSign account, you may access the documents for a limited period of time (usually 30 days) after such documents are first sent to you. After such time, if you wish for us to send you paper copies of any such documents from our office to you, you will be charged a $0.00 per-page fee. You may request delivery of such paper copies from us by following the procedure described below. Withdrawing your consent If you decide to receive notices and disclosures from us electronically, you may at any time change your mind and tell us that thereafter you want to receive required notices and disclosures only in paper format. How you must inform us of your decision to receive future notices and disclosure in paper format and withdraw your consent to receive notices and disclosures electronically is described below. Consequences of changing your mind If you elect to receive required notices and disclosures only in paper format, it will slow the speed at which we can complete certain steps in transactions with you and delivering services to you because we will need first to send the required notices or disclosures to you in paper format, and then wait until we receive back from you your acknowledgment of your receipt of such paper notices or disclosures. Further, you will no longer be able to use the DocuSign system to receive required notices and consents electronically from us or to sign electronically documents from us. All notices and disclosures will be sent to you electronically Electronic Record and Signature Disclosure created on: 2/22/2022 12:08:29 PM Parties agreed to: Kristi Grace, Maritza Martinez Unless you tell us otherwise in accordance with the procedures described herein, we will provide electronically to you through the DocuSign system all required notices, disclosures, authorizations, acknowledgements, and other documents that are required to be provided or made available to you during the course of our relationship with you. To reduce the chance of you inadvertently not receiving any notice or disclosure, we prefer to provide all of the required notices and disclosures to you by the same method and to the same address that you have given us. Thus, you can receive all the disclosures and notices electronically or in paper format through the paper mail delivery system. If you do not agree with this process, please let us know as described below. Please also see the paragraph immediately above that describes the consequences of your electing not to receive delivery of the notices and disclosures electronically from us. How to contact City of Rancho Cucamonga City Clerk's Office: You may contact us to let us know of your changes as to how we may contact you electronically, to request paper copies of certain information from us, and to withdraw your prior consent to receive notices and disclosures electronically as follows: To contact us by email send messages to: jasmin.oriel@cityofrc.us To advise City of Rancho Cucamonga City Clerk's Office of your new email address To let us know of a change in your email address where we should send notices and disclosures electronically to you, you must send an email message to us at jasmin.oriel@cityofrc.us and in the body of such request you must state: your previous email address, your new email address. We do not require any other information from you to change your email address. If you created a DocuSign account, you may update it with your new email address through your account preferences. To request paper copies from City of Rancho Cucamonga City Clerk's Office To request delivery from us of paper copies of the notices and disclosures previously provided by us to you electronically, you must send us an email to jasmin.oriel@cityofrc.us and in the body of such request you must state your email address, full name, mailing address, and telephone number. We will bill you for any fees at that time, if any. To withdraw your consent with City of Rancho Cucamonga City Clerk's Office To inform us that you no longer wish to receive future notices and disclosures in electronic format you may: i. decline to sign a document from within your signing session, and on the subsequent page, select the check-box indicating you wish to withdraw your consent, or you may; ii. send us an email to jasmin.oriel@cityofrc.us and in the body of such request you must state your email, full name, mailing address, and telephone number. We do not need any other information from you to withdraw consent.. The consequences of your withdrawing consent for online documents will be that transactions may take a longer time to process.. Required hardware and software The minimum system requirements for using the DocuSign system may change over time. The current system requirements are found here: https://support.docusign.com/guides/signer-guide- signing-system-requirements. Acknowledging your access and consent to receive and sign documents electronically To confirm to us that you can access this information electronically, which will be similar to other electronic notices and disclosures that we will provide to you, please confirm that you have read this ERSD, and (i) that you are able to print on paper or electronically save this ERSD for your future reference and access; or (ii) that you are able to email this ERSD to an email address where you will be able to print on paper or save it for your future reference and access. Further, if you consent to receiving notices and disclosures exclusively in electronic format as described herein, then select the check-box next to ‘I agree to use electronic records and signatures’ before clicking ‘CONTINUE’ within the DocuSign system. By selecting the check-box next to ‘I agree to use electronic records and signatures’, you confirm that:  You can access and read this Electronic Record and Signature Disclosure; and  You can print on paper this Electronic Record and Signature Disclosure, or save or send this Electronic Record and Disclosure to a location where you can print it, for future reference and access; and  Until or unless you notify City of Rancho Cucamonga City Clerk's Office as described above, you consent to receive exclusively through electronic means all notices, disclosures, authorizations, acknowledgements, and other documents that are required to be provided or made available to you by City of Rancho Cucamonga City Clerk's Office during the course of your relationship with City of Rancho Cucamonga City Clerk's Office.